# 52.211-12 Liquidated Damages—Construction.
Type: Clause
Prescribed in: 11.503(b)
Current version date: SEP 2000

## Prescription and Applicability

### FAR Prescription, 11.503(b)

(b) Use the clause at 52.211-12, Liquidated Damages-Construction, in solicitations and contracts for construction, other than cost-plus-fixed-fee, when the contracting officer determines that liquidated damages are appropriate (see 11.501(a)). If the contract specifies more than one completion date for separate parts or stages of the work, revise paragraph (a) of the clause to state the amount of liquidated damages for delay of each separate part or stage of the work.

### DFARS Supplementary Guidance, 211.503

(b) Use the clause at FAR 52.211-12, Liquidated Damages--Construction, in all construction contracts exceeding $900,000, except cost-plus-fixed-fee contracts or contracts where the contractor cannot control the pace of the work. Use of the clause in contracts of $900,000 or less is optional.

## Current Text

52.211-12 Liquidated Damages—Construction.

As prescribed in 11.503(b), insert the following clause in solicitations and contracts:

Liquidated Damages—Construction (SEP 2000)

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of __ [ Contracting Officer insert amount ] for each calendar day of delay until the work is completed or accepted.

(b) If the Government terminates the Contractor's right to proceed, liquidated damages will continue to accrue until the work is completed. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.

(End of clause)

[65 FR 46067, July 26, 2000]

## Suggested Questions

You can ask your AI assistant:
- Should I include this provision in my solicitation?
- Does this clause apply to commercial acquisitions?
- Does this clause apply to R&D contracts under Part 35?
- Which alternate should I use for a multiple-award contract?
- Are there any active Class Deviations that modify this clause?
- What changed in the most recent amendment?

---
Source: https://part52.dev
Generated: 2026-04-21 17:40 UTC
Reference: https://www.ecfr.gov/current/title-48/section-52.211-12