# 52.222-1 Notice to the Government of Labor Disputes.
Type: Clause
Prescribed in: 22.103-5(a)
Current version date: FEB 1997

## Prescription and Applicability

### FAR Prescription, 22.103-5(a)

(a) The contracting officer shall insert the clause at 52.222-1, Notice to the Government of Labor Disputes, in solicitations and contracts that involve programs or requirements that have been designated under 22.101-1(e).

## Current Text

52.222-1 Notice to the Government of Labor Disputes.

As prescribed in 22.103-5(a), insert the following clause:

Notice to the Government of Labor Disputes (FEB 1997)

If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this contract, the Contractor shall immediately give notice, including all relevant information, to the Contracting Officer.

(End of clause)

[48 FR 42478, Sept. 19, 1983, as amended at 61 FR 67426, Dec. 20, 1996]

## Suggested Questions

You can ask your AI assistant:
- Should I include this provision in my solicitation?
- Does this clause apply to commercial acquisitions?
- Does this clause apply to R&D contracts under Part 35?
- Which alternate should I use for a multiple-award contract?
- Are there any active Class Deviations that modify this clause?
- What changed in the most recent amendment?

---
Source: https://part52.dev
Generated: 2026-04-21 17:40 UTC
Reference: https://www.ecfr.gov/current/title-48/section-52.222-1