A community resource for the acquisition workforce
—not a .gov website
Community-maintained
part52.dev is built and maintained by members of the federal acquisition community to help with navigating DoD acquisition regulation.
Not affiliated with the U.S. Government
This site is not operated, endorsed or sanctioned by the U.S. Government. Data is sourced from public regulatory sources including eCFR.gov and acquisition.gov. Always verify against official sources.
The Revolutionary FAR Overhaul has published a revised version of this clause. The RFO version supersedes the eCFR text below for contracts using the RFO model; see the RFO deviation for applicability.
52.246-9 Inspection of Research and Development (Short Form).
As prescribed in 46.309, insert the following clause:
Inspection of Research and Development (Short Form) (APR 1984)
The Government has the right to inspect and evaluate the work performed or being performed under the contract, and the premises where the work is being performed, at all reasonable times and in a manner that will not unduly delay the work. If the Government performs inspection or evaluation on the premises of the Contractor or a subcontractor, the Contractor shall furnish and shall require subcontractors to furnish all reasonable facilities and assistance for the safe and convenient performance of these duties.
(End of clause)
[48 FR 42478, Sept. 19, 1983, as amended at 51 FR 27120, July 29, 1986]
46.309
The contracting officer shall insert the clause at 52.246-9, Inspection of Research and Development (Short Form), in solicitations and contracts for research and development when the clause prescribed in 46.307 or the clause prescribed in 46.308 is not used.
Prescription data sourced from eCFR as of 2026-06-10 03:16 UTC.
Cross-references within the prescription are not resolved automatically.
Regulatory Stack
The layers of regulation that govern this clause, from the FAR prescription through agency-specific supplements and any active deviations.
RFORFO VersionOverhauled clause text
The Revolutionary FAR Overhaul publishes a revised version of this clause. See the RFO Version tab for the controlling authority under the RFO model.
The contracting officer shall insert the clause at 52.246-9, Inspection of Research and Development (Short Form), in solicitations and contracts for research and development when the clause prescribed in 46.307 or the clause prescribed in 46.308 is not used.
Version history is sourced from the codified eCFR. Changes published only as class deviations or by the Revolutionary FAR Overhaul do not appear here until they are incorporated into the eCFR. For RFO-driven changes see the RFO Version tab and any active deviations cited above.
No version history available from eCFR.
RFO Version
Comparison of the codified eCFR text against the Revolutionary FAR Overhaul revision. Highlights show additions (green) and deletions (red, struck through).
Clause Text
Substantive changes. The RFO version differs materially from the eCFR text.
eCFR (codified)
RFO (implemented)
Unchanged
52.246-9 Inspection of Research and Development (Short Form).
eCFR (codified)
RFO (implemented)
As prescribed in 46.309, insert the following clause:
As prescribed in 46.309 , insert the following clause:
1 added, 2 removed
Inspection of Research and Development (Short Form) (APR 1984)
Inspection of Research and Development (ShortForm) (Apr 1984)
The Government has the right to inspect and evaluate the work performed or being performed under the contract, and the premises where the work is being performed, at all reasonable times and in a manner that will not unduly delay the work. If the Government performs inspection or evaluation on the premises of the Contractor or a subcontractor, the Contractor shall furnish and shall require subcontractors to furnish all reasonable facilities and assistance for the safe and convenient performance of these duties.
The Government has the right to inspect and evaluate the work performed or being performed under the contract, and the premises where the work is being performed, at all reasonable times and in a manner that will not unduly delay the work. If the Government performs inspection or evaluation on the premises of the Contractor or a subcontractor, the Contractor shall furnish and shall require subcontractors to furnish all reasonable facilities and assistance for the safe and convenient performance of these duties.
(End of clause)
(End of clause)
15 removed
[48 FR 42478, Sept. 19, 1983, as amended at 51 FR 27120, July 29, 1986]
Prescription
Minor revisions. The RFO prescription has formatting or editorial changes from the eCFR prescription.
eCFR (codified)
RFO (implemented)
Unchanged
52.246-9 Inspection of Research and Development (Short Form).: Prescription
eCFR (codified)
RFO (implemented)
1 added, 1 removed
The contracting officer shall insert the clause at 52.246-9, Inspection of Research and Development (Short Form), in solicitations and contracts for research and development when the clause prescribed in 46.307 or the clause prescribed in 46.308 is not used.
The contracting officer must insert the clause at 52.246-9, Inspection of Research and Development (Short Form), in solicitations and contracts for research and development when the clause prescribed in 46.307 or the clause prescribed in 46.308 is not used.