52.211-11 Liquidated Damages—Supplies, Services, or Research and Development.
Prescription and Applicability
FAR Prescription, 11.503(a)
(a) Use the clause at 52.211-11, Liquidated Damages-Supplies, Services, or Research and Development, in fixed-price solicitations and contracts for supplies, services, or research and development when the contracting officer determines that liquidated damages are appropriate (see 11.501(a)).
DFARS Supplementary Guidance, 211.503
(b) Use the clause at FAR 52.211-12, Liquidated Damages--Construction, in all construction contracts exceeding $900,000, except cost-plus-fixed-fee contracts or contracts where the contractor cannot control the pace of the work. Use of the clause in contracts of $900,000 or less is optional.
Current Text
52.211-11 Liquidated Damages—Supplies, Services, or Research and Development.
As prescribed in 11.503(a), insert the following clause in solicitations and contracts:
Liquidated Damages—Supplies, Services, or Research and Development (SEP 2000)
(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $__ per calendar day of delay [ Contracting Officer insert amount ].
(b) If the Government terminates this contract in whole or in part under the Default—Fixed-Price Supply and Service clause, the Contractor is liable for liquidated damages accruing until the Government reasonably obtains delivery or performance of similar supplies or services. These liquidated damages are in addition to excess costs of repurchase under the Termination clause.
(c) The Contractor will not be charged with liquidated damages when the delay in delivery or performance is beyond the control and without the fault or negligence of the Contractor as defined in the Default—Fixed-Price Supply and Service clause in this contract.
(End of clause)
[65 FR 46067, July 26, 2000]
Suggested Questions
You can ask your AI assistant:
- Should I include this provision in my solicitation?
- Does this clause apply to commercial acquisitions?
- Does this clause apply to R&D contracts under Part 35?
- Which alternate should I use for a multiple-award contract?
- Are there any active Class Deviations that modify this clause?
- What changed in the most recent amendment?