The corresponding FAR Part 17 and DFARS Part 217 have been overhauled under the RFO.
PGI replacement text is provided in the RFO deviation attachment.
View FAR Part 17
Current Content
(a) The contracting officer, without soliciting offers, may issue a written job order to a contractor that has previously executed a master agreement when—
(i) Delay in the performance of necessary repair work would endanger a vessel, its cargo or stores; or
(ii) Military necessity requires immediate work on a vessel.
(b) Follow the procedures at PGI 217.7103-4 when processing this type of undefinitized contract action.
Change History
| Detected | Type | Summary |
|---|---|---|
| detected 2026-04-17 | PGI_MODIFIED | PGI 217.7103-4 updated: 4 lines added, 1 lines removed |
View diff--- previous +++ current @@ -1 +1,4 @@ -Process this type of undefinitized contract action in accordance with DFARS Subpart 217.74. Negotiate a price as soon as practicable after the issuance of an undefinitized order and definitize the job order upon completing negotiations.+(a) The contracting officer, without soliciting offers, may issue a written job order to a contractor that has previously executed a master agreement when-- +(i) Delay in the performance of necessary repair work would endanger a vessel, its cargo or stores; or +(ii) Military necessity requires immediate work on a vessel. +(b) Follow the procedures at PGI 217.7103-4 when processing this type of undefinitized contract action. |
||